民用工程合同书[适用发包人].doc

民用工程合同书［适用发包人］ 目录 Table of Contents 1．工程范围2．合同文件3．履约保证4．工程差价和完工时间5．转包和分包6．图纸7．一般责任8．完工9．工程保险10．人员和财产的损害11．第三方责任保险12．人员的意外事故或伤害13．对承包方未履行保险义务的救济14．应当遵守的法规和规章等15．其他承包方的加入16．承包方保持施工现场的清洁17．劳工18．材料和工艺19．施工的检验20．不适当工作和材料的撤换21．工程的中断22．开始和终止的时间23．工期的延展24．工程的进度25．工程的延期的损失计算26．工程完工的证明27．工程缺陷的保证和不履行义务的责任28．合同条款的变更、增加和删减29．由于工程数量变更所做的合同价格的调整30．设备、临时工程和材料31．工程量的计算32．临时款项33．付款和保留的余额34．对承包方违约的救济和权力35．特殊风险36．合同的落空及其补偿37．争议的解决——仲裁38．通知39．发包方违约40．文字41．应当遵守的法律 1.　Scope of Work2.　Contract Documents3.　Performance Security4.　Value of Work and Completion Time5.　Assignment and Sub- letting6.　Drawings7.　General Obligations8.　Completion of Works9.　Insurance of Works10.　Damage to Persons and Property11.　Third Party Insurance12.　Accident or Injury to Persons13.　Remedy on Contractors Failure to Insure14.　Compliance with Status and Regulations ，etc.15.　Access to Other Contractors16.　Contractor to Keep Site Clean17.　Labor18.　Materials and Workmanship19.　Inspection of Operations20.　Removal of Improper Work and Materials21.　Suspension of Work22.　Commencement Time and Time for Completion23.　Extension of Time for Completion24.　Rate of Progress25.　Liquidated Damages for Delay26.　Certification of Completion of Work27.　Guarantee against Defects and Liability for Defective Work28.　Alterations， Additions and Omissions29.　Adjustment of Contract Price Due to Variations in Quantities30.　Plant， Temporary Works and Materials31.　Measurement of Quantities32.　Provisional Sums33.　Payment and Retention34.　Remedies and Power on Default by Contractor35.　Special Risks36.　Frustration and Payments Thereof37.　Settlement of Disputes - Arbitration38.　Notice39.　Default of Employer40.　Language41.　Laws to Be Observed 本合同由??????????代表的??????????（公司），以下称“发包方”，和??????????代表的??????????（公司），以下称“承包方”，于??????????年??????????月在??????????（地点）订立。承包方在??????????国注册为法人，其主要办事机构位于??????????，其代表已经被授权签订约束该法人的合同。 This Contract is made at_________， Chesiville，Parche